Stay Plugged In With Canon
Latest News & Updates

In many construction projects, change orders are a normal part of adapting a design to evolving needs. However, problems arise when owners reject valid change requests without substantive justification, or when they delay approvals to gain leverage. Contractors facing this pattern must first ensure the change is properly documented, including a clear description of scope, cost, and schedule impact. A well-prepared change order presents a fair price, a reasonable timeline, and the specific contract references that authorize the adjustment. Beyond paperwork, proactive communication can reveal concerns early. The key is to separate technical disputes from opportunistic holds, preserving the entitlement while avoiding unnecessary quarrels that stall progress.

To preserve entitlement, contractors should align every change request with the contract's formal process. That means submitting written change orders promptly, with attached drawings, specs, and a thorough impact analysis. If an owner refuses to sign without reason, the contractor should reference the contract clause governing changes and the deadline for approvals. Keeping a transparent trail of correspondence is essential because it creates a risk ledger that can be used if escalation becomes necessary. When owners withhold consent, a measured approach—documented negotiations, a clear rationale for the change, and a proposed schedule—helps avoid claim disputes and demonstrates good-faith intent to complete the project efficiently.

The first response is to formalize the issue through a structured meeting that includes all stakeholders. In that session, present the change order alongside a detailed impact summary, including labor, material, and equipment implications. Invite questions, but keep discussions focused on objective criteria rather than emotional objections. If the owner doubles down on rejection, propose conditional approvals or staged implementation as compromise. Throughout, maintain a precise log of decisions, amendments, and any concessions. This method signals credibility and readiness to move forward, while preserving the contractor’s right to compensation for legitimately incurred costs and foregone profits due to the owner’s delays.

A crucial practice is to prepare and preserve a “baseline entitlement” package. This consists of original contract terms, the applicable change-order clause, and a proven record of the actual costs and schedule impacts arising from the requested change. When owners repeatedly deny without justification, reference to the baseline can prevent silent underpayments. Include a quantified estimate of disruption to subcontractors and critical-path activities. A well-structured entitlement package makes it harder for owners to sidestep their contractual duties and strengthens the contractor’s leverage in negotiations or, if needed, in dispute resolution forums.

Another key tactic is to separate the monetary claim from the scheduling disruption. By presenting a request for price adjustment and a separate schedule impact analysis, you give owners clear choices and reduce the temptation to dodge responsibility. The price discussion should be grounded in market rates and backed by supplier quotes or unit costs. For schedule impacts, map out the critical path and identify how the change affects milestones, handover dates, and lien rights. Clear separation helps keep conversations productive, preserving business relationships while ensuring the contractor’s entitlements are not buried under ambiguous objections.

When owners delay or reject without substantive justification, escalation becomes a legitimate option. Begin with a formal notice of delay or impairment, referencing the contract’s dispute resolution provisions. If informal talks stall, move to a mediated session with a neutral facilitator. The purpose is not punishment but timely resolution that protects cash flow and the project’s critical path. Throughout escalation, maintain objective language, avoid personal attacks, and gather additional evidence of the owner’s pattern of withholding approvals. Demonstrating due process shows that the contractor is acting in good faith and seeking a fair, contractual remedy rather than confrontation.

A practical safeguard is to align your change orders with lien rights and payment timelines. Ensure the entitlement is receivable at the point the owner withholds approval or delays payment. When a change is approved, prompt payment documentation should accompany the update—copies of invoices, updated schedules, and revised procurement orders. If the owner disputes the value, provide a detailed cost justification and reference market rates for comparable work. The goal is to maintain cash flow integrity while preserving the ability to recover costs through the contract’s remedies if the dispute cannot be resolved promptly.

While pursuing entitlement, maintain professional boundaries and transparency with the project team. Notify project managers and subcontractors of the status of each change, including approvals, rejections, and anticipated impacts. This practice helps prevent miscommunications that could lead to additional claims or delays. It also reinforces accountability—everyone understands what has been agreed, what remains unsettled, and how the change affects subcontractor scopes. When stakeholders see consistent, fact-based reporting, they are better prepared to collaborate on constructive solutions rather than exploiting disagreements to stall work.

In some cases, owners may repeatedly reject valid changes citing concerns about budget, risk, or schedule. A constructive response is to propose risk-sharing arrangements or value engineering alternatives that meet the project’s objectives without compromising safety or quality. These negotiations should be anchored by a clear evaluation framework: define the acceptable range of options, the associated costs, and the expected effect on completion. By offering alternatives, the contractor demonstrates flexibility while preserving the fundamental entitlement to compensation for work already performed or committed to under the approved scope.

When alternatives are not acceptable, document a clean, formal claim for the change. The claim should include a narrative of the change, the contractual basis for entitlement, the supporting calculations, and the cumulative effect on the project budget and timeline. Attach all relevant correspondence, quotes, and change orders. A well-prepared claim reduces ambiguity and strengthens the contractor’s position if the matter advances to litigation or arbitration. It also provides a clear, auditable trail that the owner cannot ignore without risking substantive legal exposure.

In the long run, develop a proactive risk management plan focused on change order governance. This plan should define who approves what, when approvals are due, and how changes impact the critical path. Regular dashboards for owners and project teams can help highlight potential deltas early, giving everyone a chance to adjust before costs balloon. The plan also outlines escrow or hold-back mechanisms for disputed amounts, ensuring cash flow continuity while preserving the right to seek remedy. A consistently applied governance process reduces the frequency of arbitrary rejections and fosters cooperative problem solving.

Finally, cultivate relationships built on trust and accountability. While it is essential to defend entitlements, maintain professional courtesy with owners and their representatives. Offer prioritization options that keep critical milestones on track when legitimate changes arise. Schedule regular status updates, invite feedback, and acknowledge valid concerns. By showing a commitment to shared objectives, contractors can minimize adversarial dynamics and create an environment where changes are evaluated on merit, not politics. In doing so, entitlement protections become a natural byproduct of thoughtful governance and constructive collaboration.